Introduction These Terms of Service Agreement govern the services provided by Aesthetic Home Renovations, is  a home renovation company specialising in bathroom and kitchen remodels (Andrew Youssef, Director) to the client (“Client,” “You,” or “Your”). By engaging in services with us, you agree to the terms outlined below.

Scope of Services The Contractor agrees to provide remodelling and renovation services for bathrooms and/or kitchens as specified in the project proposal, which may include design, construction, installation, and any other related services (“Services”). The specific scope of the project will be outlined in a separate written proposal or contract, which must be signed by both parties before work commences.

Estimates and Pricing

• Estimates: Any preliminary estimates provided are based on initial discussions and are subject to change based on further evaluation or unforeseen circumstances during the project. All estimates are non-binding unless specified otherwise.
• Final Pricing: The final price will be confirmed in the project proposal/contract. The Client will be provided with a detailed breakdown of labor, materials, and other expenses.
• Payment Terms: Payments are typically made in installments, with a deposit due before work commences. The deposit amount and schedule will be specified in the project proposal. Payments for additional services or changes made during the project will be invoiced accordingly.

Changes and Adjustments Any changes to the scope of work after the contract has been signed must be documented and agreed upon by both parties in writing. This may include alterations to design, materials, or schedule. Additional costs resulting from such changes will be added to the final invoice.

Client Responsibilities

• Access to Property: The Client agrees to provide the Contractor with access to the property during normal business hours for the duration of the project.
• Utilities: The Client will ensure that necessary utilities (e.g., electricity, water, gas) are available for the Contractor’s use during the project.
• Permits and Approvals: The Client is responsible for obtaining any necessary permits, inspections, or approvals required by local authorities for the renovation project, unless otherwise agreed upon.

Timeline and Completion

• Project Duration: The project timeline will be outlined in the project proposal, with an estimated start and completion date. While we will make every effort to meet this timeline, delays may occur due to weather, supply chain issues, or unforeseen complications. Any delays will be communicated promptly.
• Completion: The project will be considered complete once all work specified in the proposal is finished to the satisfaction of both parties, and any required inspections or approvals have been obtained.

Warranty The Contractor offers a warranty on the workmanship for each specific project from the date of project completion. This warranty covers defects in labor but does not cover damages caused by misuse, neglect, or normal wear and tear. Manufacturer warranties on materials (such as cabinetry, fixtures, etc.) will be passed on to the Client.

Liability and Insurance The Contractor maintains general liability insurance to cover damages or accidents that may occur during the project. The Contractor is not responsible for damage to property or personal injury resulting from conditions beyond its control, including but not limited to structural issues, pre-existing damage, or acts of nature.

Termination Either party may terminate the contract in writing if the other party fails to meet the obligations outlined in the agreement. If the Client terminates the project before completion, they will be responsible for any completed work and materials ordered. If the Contractor terminates the agreement, the Client will be entitled to a refund of any deposits for work not yet performed.

Dispute Resolution In the event of a dispute, the parties agree to first attempt to resolve the issue through informal negotiation. If this does not result in a satisfactory resolution, the dispute may be resolved through binding arbitration or mediation in accordance with the laws of [State/Province/Country].

Confidentiality Both parties agree to keep confidential any proprietary information shared during the course of the project, including design concepts, business strategies, and pricing information.

Indemnity The Client agrees to indemnify and hold harmless the Contractor from any claims, damages, or losses arising from the Client’s negligence, misuse of the property, or failure to comply with legal requirements related to the property.

Governing Law This Agreement shall be governed by and construed in accordance with the laws of [State/Province/Country]. Any legal action arising from this Agreement will be filed in the appropriate court within the jurisdiction of [State/Province/Country].

Entire Agreement This Agreement constitutes the entire understanding between the parties and supersedes any prior agreements or discussions. Any amendments or modifications to this Agreement must be in writing and signed by both parties.

Client Acknowledgment

The Client acknowledges that they have read, understood, and agree to the Terms of Service outlined above.